CYLINDER ASSEMBLY,A

Agency	DEPT OF DEFENSE
Solicitation Number	N0010427QLA13
Notice Type	Solicitation
NAICS	333613
Set-Aside	No Set-Aside
Place Of Performance
Posted	Oct 28, 2026
Source	Federal — SAM.gov
Response Deadline	Nov 12, 2026 6 days left as of Nov 6, 2026
Time Left	6 days left as of 2026-11-06
Primary	Telephone: 7176057322 · [email protected]
Official Notice	View On SAM.gov

About this opportunity

CONTACT INFORMATION|4|N713.23|GJG|7712290566|[email protected]| ITEM UNIQUE IDENTIFICATION AND VALUATION (JAN 2023)|19|||||||||||||||||||| INSPECTION OF SUPPLIES--FIXED-PRICE (AUG 1996)|2||| WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (JAN 2023)|16|Combo Invoice and Receiving||TBD|N00104|TBD|TBD|See Schedule|TBD|||TBD|||||| NAVY USE OF ABILITYONE SUPPORT CONTRACTOR - RELEASE OF OFFEROR INFORMATION (3-18))|1|WSS| MANDATORY USE OF WORKFLOW PRO (WFP) MOD ASSIST MODULE|1|| BUY AMERICAN-FREE TRADE AGREEMENTS-BALANCE OF PAYMENTS PROGRAM-BASIC (FEB 2024)|11|||||||||||| NOTICE OF CYBERSECURITY MATURITY MODEL CERTIFICATION LEVEL REQUIREMENTS (NOV 2025))|1|| SMALL BUSINESS SUBCONTRACTING PLAN (DOD CONTRACTS)-BASIC (DEV 2026-O0037)(JUL 2026))|2||| OPTION FOR INCREASED QUANTITY (MAR 1989)|1|365 Days| CONTRACTOR PURCHASING SYSTEM ADMINISTRATION-BASIC (DEV 2026-O0015)(JUL 2026)|1|| SECURITY PROHIBITIONS AND EXCLUSIONS (CLASS DEVIATION 2026-O0025)(FEB 2026)|7|||||||| BUY AMERICAN-FREE TRADE AGREEMENTS-BALANCE OF PAYMENTS PROGRAM CERTIFICATE-BASIC (FEB 2024))|5|||||| BUY AMERICAN-BALANCE OF PAYMENTS PROGRAM CERTIFICATE-BASIC (FEB 2024)|1|| ALTERNATE A, ANNUAL REPRESENTATIONS AND CERTIFICATIONS (DEVIATION 2026-O0043)(FEB 2026))|13|||||||||||||| NOTICE OF PRIORITY RATING FOR NATIONAL DEFENSE, EMERGENCY PERPARDENESS, AND ENRGY PROGAM USE (APRIL 2008))|2||| Accelerated delivery is encouraged and accepted before the delivery date(s) listed in the schedule. ^^ All freight is FOB Origin. This RFQ is for repair. The resultant award of this solicitation will be issued bilaterally, requiring the contractor's written acceptance prior to execution. Verify nomenclature, part number, and NSN prior to responding. The Government is seeking a Repair Turnaround Time (RTAT) of: 180 Days Government Source Inspection (GSI) is required. Please note freight is handled by Navy CAV or Proxy CAV as stated in NAVSUPWSSFA24 or NAVSUPWSSFA25. IMPORTANT NOTE: Any asset for which the contractor does not meet the required RTAT will incur a price reduction per unit/per month the contractor is late - any delay determined to be excusable (e.g. Government Delay) will not result in a price reduction. If a price reduction is required due to unexcusable contractor delay, the Contracting Officer will implement the aforementioned price reduction via a ""reconciliation modification"" at the end of the contract performance. Price reductions made pursuant to this section shall not limit other remedies available to the Government for failure to meet required RTATs, including but not limited to the Government's right to terminate for default. In reference to the above important note, the contractor provides the following price reduction amount per unit per month the contractor does not meet the RTAT: $__________, up to a maximum of: $_________. The Government intends to add an option quantity to the resultant contract. In reference to the option quantity, the Government may increase the quantity of supplies called for in the Schedule at the unit price specified. The Contracting Officer may exercise the option by written notice to the Contractor within the number of days in FAR 52.217-6 herein. Delivery of the added items shall continue at the same rate as the like items called for under the contract, unless the parties otherwise agree. Your quote should include the following information: QUOTE AMOUNT AND RTAT Unit Price:__________ Total Price:__________ Repair Turnaround Time (RTAT): _______ days If your company is not quoting the Government's Required Repair Turnaround Time (RTAT) or earlier, provide your company's capacity constraints? _________________________________________________________________ _________________________________________________________________ _________________________________________________________________ Repair Turnaround Time (RTAT): the resultant contractual delivery requirement is measured from asset Return to the date of asset acceptance under the

Who can apply

Set-aside: NONE — as stated in the official notice: “NONE”. Verify eligibility on the official notice before bidding.

Source: SAM.gov. Verify every deadline on the official notice.